Triple Point Technology Inc v PTT Public Co Ltd

Hearings

England & Wales

23 Aug 2017 [2017] EWHC 2178 (TCC), QBD (Jefford J)

17 Jan 2018 [2018] EWHC 45 (TCC), QBD (Jefford J)

05 Mar 2019 [2019] EWCA Civ 230; [2019] 1 WLR 3549; [2019] 3 All ER 767; [2019] 2 All ER (Comm) 810; [2019] WLR (D) 126, CA (Lewison, Floyd LJJ, Sir Rupert Jackson)

06 Nov 2019 (appn all) [2019] 1 WLR 6748; Case details, SC(E) (Lord Reed DPSC, Lady Black, Lord Kitchin JJSC)

16 Jul 2021 [2021] UKSC 29; [2021] AC 1148; [2021] 3 WLR 521; [2022] 3 All ER 601; [2022] 2 All ER (Comm) 93; [2021] BLR 555; [2021] WLR(D) 411, SC(E) (Lord Hodge DPSC, Lady Arden, Lord Sales, Lord Leggatt, Lord Burrows JJSC)

Subject Matter

CONTRACT — Construction — Liquidated damages clause — Clause providing for liquidated damages for contractor’s delay in completing work — Employer terminating contract after dispute with contractor — Whether liquidated damages clause applying where contractor not completing work

[2019] EWCA Civ 230; [2019] 1 WLR 3549; [2019] 3 All ER 767; [2019] 2 All ER (Comm) 810; [2019] WLR (D) 126, CA

CONTRACT — Construction — Liquidated damages clause — Contract for supply of software system providing for liquidated damages for contractor’s delay in completing work — Contract also providing for cap on damages payable by contractor for breach of contract save in relation to “negligence” — Whether liquidated damages clause applying where contractor never completing work — Whether “negligence” exception to damages cap limited to tort of negligence or including negligent performance of contractual obligations — Whether damages cap applying to liquidated damages

[2021] UKSC 29; [2021] AC 1148; [2021] 3 WLR 521; [2022] 3 All ER 601; [2022] 2 All ER (Comm) 93; [2021] BLR 555; [2021] WLR(D) 411, SC(E)

Appellate History

Triple Point Technology Inc v PTT Public Co Ltd [2017] EWHC 2178 (TCC), QBD

Decision of Jefford J reversed in part

Triple Point Technology Inc v PTT Public Co Ltd [2019] EWCA Civ 230; [2019] 1 WLR 3549; [2019] 3 All ER 767; [2019] 2 All ER (Comm) 810; [2019] WLR (D) 126, CA

Triple Point Technology Inc v PTT Public Co Ltd [2019] EWCA Civ 230; [2019] 1 WLR 3549; [2019] 3 All ER 767; [2019] 2 All ER (Comm) 810; [2019] WLR (D) 126, CA

Decision of the Court of Appeal reversed in part

Triple Point Technology Inc v PTT Public Co Ltd [2021] UKSC 29; [2021] AC 1148; [2021] 3 WLR 521; [2022] 3 All ER 601; [2022] 2 All ER (Comm) 93; [2021] BLR 555; [2021] WLR(D) 411, SC(E)

Commentary

UK Supreme Court Blog
Case Preview: Triple Point Technology Inc v PTT Public Company Ltd Case comment

Case Comment – Triple Point Technology Inc v PTT Public Company Ltd [2021] UKSC 29 Case comment

Subscribe or Register to access the full case information page. Registered users can access three Law Reports, three case information pages and perform three Case Genie searches per month. If you already have an ICLR account please log in. For other queries or to request a free trial please contact ICLR.

MoJ users should log in here.

We use cookies on this website, you can read our Privacy and Cookies Policy. To use website as intended please Accept Cookies