The WLR Daily case summaries
[2019] WLR (D) 126
Court of Appeal
Triple Point Technology, Inc v PTT Public Co Ltd
[2019] EWCA Civ 230
Lewison, Floyd LJJ, Sir Rupert Jackson
2019 Jan 16, 17; March 5
Contract— Construction— Liquidated damages clause— Clause providing for liquidated damages for delay— Contractor completing first section of work late— Contractor then suspending work and employer terminating agreement— Whether liquidated damages clause applying